Combine Solicitation – Generator Reconditioning and Rewind USCGC WALNUT (WLB-205)

Notice Type: Combine Solicitation

Posted Date: 18-NOV-11

Office Address: Department of Homeland Security; United States Coast Guard (USCG); USCG Surface Forces Logistics Center (SFLC) Procurement Branch 2; 1301 Clay St.,Suite 807N Oakland CA 94612-5249

Subject: Generator Reconditioning and Rewind USCGC WALNUT (WLB-205)

Classification Code: 20 - Ship and marine equipment

Solicitation Number: HSCG85-12-Q-P45372

Contact: Jack Rodman, Contract Specialist, Phone (510) 637-5988, Fax (510) 637-5877, Email [email protected] - Jay S McReynolds, Contract Specialist, Phone 510-637-5975, Fax 510-637-5978, Email [email protected]

Setaside: Total Small BusinessTotal Small Business

Place of Performance (address): USCGC WALNUT (WLB-205) ISC Area 4, Bldg 554, Sand Island Access RoadHonolulu, HI

Place of Performance (zipcode): 96819

Place of Performance Country: US

Description: Department of Homeland Security

United States Coast Guard (USCG)

USCG Surface Forces Logistics Center (SFLC) Procurement Branch 2

This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in FAR Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; quotations are being requested and a separate written solicitation will not be issued. Solicitation number HSCG85-12-Q-P45372 is issued as a Request for Quotations (RFQ). HSCG85-12-Q-P45372 and incorporated provisions and clauses are those in effect through Federal Acquisition Circular 05-46. This requirement is being solicited as a Total Small Business Set-aside using Simplified Acquisition Procedures per FAR Subpart 13. The Small Business Size Standard for NAICS Code 336611 is 1000 employees. A Firm-Fixed Price Contract for the base items is anticipated. The anticipated award date is on or about November 25, 2011. Work covered by this solicitation shall be completed within thirty-two (32) calendar days from the date the vessel becomes available to the contractor. The availability is scheduled to start on or about November 28, 2011 and end on or about December 30, 2011. The Place of Performance will be at the USCGC WALNUT and contractor's facility. The home port is located ISC Area 4, Bldg 554, Sand Island Access Road, Honolulu, HI 96819. For ship access, please contact CWO Todd Drake at (808) 842-2865. The government intends to award from this solicitation to the responsible vendor whose quote conforming to the solicitation provides the best value. OMBUDSMAN NOTICE

NOTICE FOR FILING AGENCY PROTESTS

It is the policy of the Coast Guard to issue solicitations and make contract awards in a fair and timely manner. The Ombudsman Program for Agency Protests (OPAP) was established to investigate agency protest issues and resolve them without expensive and time-consuming litigation. OPAP is an independent reviewing authority that is empowered to grant a prevailing protester essentially the same relief as the General Accounting Office (GAO).

Interested parties are encouraged to seek resolution of their concerns within the Coast Guard as an Alternative Dispute Resolution (ADR) forum, rather filing a protest with the GAO or some external forum. Interested Parties may seek resolution of their concerns informally or opt to file a formal agency protest with the contracting officer or Ombudsman.

INFORMAL FORUM WITH THE OMBUDSMAN. Interested parties who believe that a Coast Guard procurement is unfair or otherwise defective should first direct their concerns to the cognizant contracting officer. If the contracting officer is unable to satisfy the concerns, the interested party is encouraged to contact the coast Guard Ombudsman for Agency Protests. Under this informal process, the agency is not required to suspend contract award performance. Use of an informal forum does not suspend any time requirement for filing a protest with the agency or other forum. In order to ensure a timely response, interested parties should provide the following information to the Ombudsman: solicitation/contract number, contracting officer, and solicitation closing date (if applicable).

FORMAL AGENCY PROTEST WITH THE OMBUDSMAN: Prior to submitting a formal agency protest, protesters must first use their best efforts to resolve their concerns with the contracting officer through open and frank discussions. If the protester's concerns are unresolved, an independent review is available by the Ombudsman. The protester may file a formal agency protest to either the contracting officer or as an alternative to that, the Ombudsman under the OPAP program. Contract award or performance will be suspended during the protest period unless contract award or performance is justified, in writing, for urgent and compelling reasons or is determined in writing to be in the best interest of the Government. The agency's goal is to resolve protests in less than 35 calendar days from the date of filing. Protests shall include the information set forth at FAR 33.103(d)(2). If the protester fails to submit the required information, resolution of the protest may be delayed or the protest may be dismissed. This will not preclude re-filing of the protests to meet the requirement. To be timely, protests must be filed within the

period specified in FAR 33.103(e). Formal protests filed under the OPAP program should be forwarded to the address below:

Commandant (GG-913) U.S.Coast Guard Headquarters Acquisition Planning and Performance Measurement 1900 Half St. SW, Room 11-0402 Washington, DC 20593 Telephone: (202) 372-3692 Fax: (202) 475-3904

DESCRIPTION OF WORK A. The Contractor shall provide all labor, material, parts, equipment, and special tools to complete a stator assembly rewind and that all other windings can be reconditioned on the Number 2 SSDG. If any assembly designated for rewinding can be satisfactorily restored by reconditioning only, the Government shall receive an equitable adjustment for the rewinding work not performed. All work shall be done in accordance with attached specification. B. The Contractor shall provide all labor material, parts, equipment and special tools to recondition the Number 1 SSDG. All work shall be done in accordance with attached specification. C. Both the Number 1 and Number 2 Generators will be removed from the vessel and repaired at the contractor's facility. Upon completion the contractor shall re-install and align the regenerators. All work shall be done in accordance with attached specification. D. The contractor shall provide the services of a certified technical representative for the removal and reinstallation of both Generators. E. The contractor shall provide an EASA qualified Electrical Machine Shop for the rewind and recondition of the generators.

CERTIFICATIONS (a) All welding and brazing shall be accomplished by trained welders who have been certified by the applicable regulatory code performance qualification procedures. Must be provided with quotation (b) Electrical Apparatus Service Association (EASA) Certification. Must be provided with quotation.

Each quoter shall furnish the information required by the solicitation. PRICING DATA:

Base Contract Line Item Numbers (CLINs) are marked as "D" for Definitive. Optional CLINS are marked "O" for Optional. Insert unit prices in all CLINs listed in the Schedule unless "NSP" is printed in the Unit Price column for any CLIN. "NSP" in the section means "Not Separately Priced."

TRAVEL AND PER DIEM:

CLIN C, "Travel and Per Diem", is applicable only to Contractors not within the local commuting area (50 miles) of the vessels location. It is anticipated that any Contractors within the 50 mile commuting area will enter "zero" (0) or "N/A" for the unit and extended price for this CLIN, on the Schedule of Supplies or Services. The place of performance will be located at ISC Area 4, Bldg 554, Sand Island Access Road, Honolulu, HI 96819.

ITEM DESCRIPTION UNIT PRICE UNIT QTY EXTENDED PRICE D-001 Ship Service Diesel Generator, Overhaul JOB 1 O-00A Composite Labor Rate Hour 110 D-00B GFP Report NSP EA NSP D-00C Travel and Per-diem JOB Total Price of Definite Items Total Price of Option Items Total Price of Definite and Optional Items SEE PRICING SHEET ATTACHMENT FOR QUOTES

Refer questions to Jack Rodman, Contract Specialist (510) 637-5988. Quotes must arrive no later than 11:00 am. PST, November 23, 2011. Quotations may be sent via electronic mail (e-mail) to [email protected], the US Postal Service, or hand delivered to: USCG Surface Forces Logistics Center, Attn: Jack Rodman, 1301 Clay Street, Suite 807N, Oakland California 94612-5249. As per FAR 52.215-5 FACSIMILE PROPOSALS (OCT 1997), offerors may submit facsimile quotes as responses to this solicitation. E-mail and Facsimile proposals are subject to the same rules as paper proposals. The telephone number for receiving facsimiles is (510) 637-5877. No hard copies of this combined synopsis/solicitation will be issued.

Inspection and Acceptance is at destination.

CONTRACT CLAUSES

(1) The provision at FAR 52.212-1, Instructions to Offerors - Commercial Items (Jun 2008) applies to this acquisition (with the exception of paragraph f).

(2) FAR 52.212-2, Evaluation--Commercial Items (Jan 1999)

The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:

The offeror shall identify at least two (2) relevant (construction, overhaul, repair and alteration of ships) federal, state or local government or private contracts performed during the last three (3) years. For each contract, list:

a. Contract number and customer point of contact (including two (2) points of contact With telephone numbers) b. Dollar value of the contract (Original and Final) c. Type of service performed and whether Prime or subcontractor d. Required completion date for the contract e. Date the services were actually completed f. Ship Name, Hull Number g. Contract type (FFP, IDIQ, Requirement, Cost Type) h. Percentage of growth in contract price (Additional work divided by award price)

If subcontracting arrangement is proposed, the above data must also be provided for each first tier subcontractor. If a joint effort or teaming arrangement is proposed, highlight previous experience with the proposed team or subcontractor.

PAST PERFORMANCE:

The past performance evaluation will take into account the guidelines outlined at FAR 15.305(a) (2) Past Performance Evaluation. The contractor's past performance will be evaluated according to the following factors and questions: - Quality of Product or Service Did the customer get what was specified Did the customer consider the final product high in quality If warranty issues arose, were they promptly corrected - Timeliness of Performance Was the contract completed on time If not, reason why not (growth work, contractor delayed, government delayed ) - Business Relations How was the customer service Was the contractor committed to customer satisfaction Would you use this company again (Why/Why not) - Subcontracts Were subcontracts involved Comments

In evaluating contractors past performance, the government intends to also review U.S. Coast Guard Contractor Performance Reports and other existing past performance ratings on relevant contracts. General trends in a contractor's performance will also be considered.

PRICE: The Total evaluated price of the offeror will be determined by totaling the proposed prices of all the Definite Items, and plus the composite labor hour. a. Definite Items: These are items, which, if there is an award at all will be awarded. The proposal shall be evaluated to include the price for each definite item.

b. Composite Labor Hour Rate: The offeror shall be evaluated to include the offer price for the Composite Labor Hour Rate multiplied by the estimated quantity of hours. c. Offeror's price shall represent the best price in response to the request for quotes. The price shall be evaluated to determine fairness and reasonableness

****Past Performance is approximately equal Price****

(End of Provision) (3) FAR 52.212-3, Offeror Representations and Certifications - Commercial Items. (May 2011) applies to this acquisition.

Offerors are required to submit, a completed copy of the provision at Offeror Representations and Certifications - Commercial Items, with their quote. An offeror shall complete only paragraph (j) of this provision if the offeror has completed the annual representations and certifications electronically at http://orca.bpn.gov. If an offeror has not completed the annual representations and certifications electronically at the ORCA website, the offeror shall complete only paragraphs (b) through (i) of this provision. (End of Provision)

(4) FAR 52.212-4, Contract Terms and Conditions - Commercial Items (Jun 2010) and below addendum applies to this acquisition.

FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: http://www.arnet.gov/far/index.html

FAR 52.211-15 Defense Priority and Allocation Requirements (APR 2008) DO A3 Rating FAR 52.215-5 Facsimile Proposal (OCT 1997) FAR 52.223-3 Hazardous Material Identification and Material Safety Data (JAN 1997) Alternate I (JUL 1995) FAR 52.242-2 Production Progress Reports (APR 1991) HSAR 3052.211-70 Index for Specifications (DEC 2003) HSAR 3052.217-91 Performance (DEC 2003) HSAR 3052.217-92 Inspection and Manner of Doing Work (DEC 2003) HSAR 3052.217-93 Subcontracts (DEC 2003) HSAR 3052.217-95 Liability and Insurance (DEC 2003) HSAR 3052.217-96 Title (DEC 2003) HSAR 3052.217-97 Discharge of liens (DEC 2003) HSAR 3052.217-98 Delays (DEC 2003) HSAR 3052.217-99 Department of Labor Safety and Health Regulations for Ship Repair (DEC 2003) HSAR 3052.217-100 Guarantee (JUN 2006) HSAR 3052.222-70 Strikes or Picketing Affecting Timely Completion of the Contract Work (DEC 2003) HSAR 3052.222-71 Strikes or Picketing Affecting Access to a DHS Facility (DEC 2003) HSAR 3052.223-90 Accident and Fire Reporting (DEC 2003) HSAR 3052.242-71 Dissemination of Contract Information (DEC 2003) HSAR 3052.242-72 Contracting Officer's Technical Representative (DEC 2003) FAR 52.217-7 OPTION FOR INCREASED QUANTITY - SEPARATELY PRICED LINE ITEM (MAR 1989) - VARIATION

The Government may require the performance of the numbered line items, identified in the Schedule as option items, at the unit prices stated in the Schedule. The option quantities shown in the Schedule are estimates only. The Government has the right to require performance of these items at the quantities deemed necessary. Therefore, the Government may exercise an option item on more than one occasion during the contract performance period. The Contracting Officer will provide initial notification of the exercise of an option either verbally, by facsimile, or by e-mail. When time is of essence initial notification will be provided verbally followed within 24 hours by an e-mail or facsimile of confirmation. A contract modification will be executed shortly thereafter to include those options wherein exercise notification was provided. Such options may be exercised at any phase during the contract performance period as stated herein, or any extension of the performance period. To maintain the contract performance period the Contractor shall commence performance of an option item immediately upon receiving initial notification; but, not later than 24 hours thereafter, unless proper sequencing of the work requires a delay in beginning performance of the option. In that case, the option item shall be commenced as soon as proper sequencing permits. The exercise of any option item listed in the Schedule will not normally extend the contract performance period. However, the Contracting Officer may consider a request by the Contractor for contract extension if an option is exercised after 50% of the contract performance period has expired.

(End of Clause)

HSAR 3052.223-70 REMOVAL OR DISPOSAL OF HAZARDOUS SUBSTANCES - APPLICABLE LICENSES AND PERMITS (JUN 2006)

The Contractor shall have all licenses and permits required by Federal, state, and local laws to perform hazardous substance(s) removal or disposal services. If the Contractor does not currently possess these documents, it shall obtain all requisite licenses and permits within fifteen (15) days after date of award. The Contractor shall provide evidence of said documents to the Contracting Officer or designated Government representative prior to commencement of work under the contract.

(End of clause)

REQUIRED INSURANCE

The Contractor shall, at its own expense, procure and maintain the following kinds of insurance with respect to performance under the contract. In accordance with HSAR 3052.228-70, Insurance (DEC 2003), the Contractor shall furnish the Contracting Officer with proof of insurance for the duration of the contract, including: 1. Ship Repairer's Liability - $500,000 per occurrence. 2. Comprehensive General Liability - $500,000 per occurrence. 3. Full insurance coverage in accordance with the United States' Longshoremen's and Harbor Worker's Act. 4. Full insurance coverage in accordance with the State's Workmen's Compensation Law (or its equivalent) for all places of performance under this contract. The insurance certificate must provide the name of the US Coast Guard vessel and the contract and/or solicitation number as specifically insured.

INSPECTIONS

Except as specified elsewhere, the U.S. Coast Guard shall rely on the Contractor to accomplish all inspection and testing needed to ensure that the work conforms to contract quality requirements.

Records of all inspection work by the Contractor shall be kept complete and available to the Government during the term of this contract and for such longer period as may be specified elsewhere in this contract.

The name and telephone number of the U.S. Coast Guard Inspector will be provided after the award of a contract resulting from this solicitation.

GROWTH WORK

(a) The Contractor shall not perform growth work without the Contracting Officer's authorization. Growth work is work within the scope of the contract, which has not been previously priced as a pre-priced CLIN. The Contracting Officer reserves the right to contract for growth work on the basis of a negotiated, firm, fixed price, when it is in the best interest of the Government. If a firm-fixed price contract is awarded, and during the performance period a repair within scope is identified but the Contracting Officer and Contractor are unable to agree on the cost of the work, a bilateral modification may be incorporated into the contract using a Time and Materials modification for this specific repair. In this situation, FAR 52.212-4, Alternate I, will be incorporated.

(b) The Contractor shall furnish a price breakdown directly to the Contracting Officer, itemized as required by the Contracting Officer, of any proposal submitted for a contract modification. Unless otherwise directed, the breakdown shall be submitted on an SFLC 002 proposal form provided at the arrival conference permitting an analysis of all materials, labor, equipment, subcontract, overhead costs, and profit covering all work involved in the change/modification whether such work was deleted, added or changed. Any amount claimed for subcontracts shall be supported by a separate, similar price breakdown. If the proposal includes a request for a time extension, justification shall be furnished with the proposal.

(c) This clause is to be used in conjunction with the clause COMPOSITE LABOR RATE incorporated into this solicitation. The Contractor is required to have and/or furnish all tools and equipment incidental to each bench trade. Supplies such as wiping rags, hacksaw blades, sandpaper, welding wire, helium, etc., are also to be furnished by the Contractor. Other materials are to be charged at regular rates and prices currently in effect and as agreed to by the Contracting Officer. Material shall be best commercial quality available except where a precise specification is indicated in which case the specification shall apply, e.g., MILSPEC, FEDERAL SPEC.

COMPOSITE LABOR RATE:

The composite labor rate offered shall be the sole labor hour rate used to price the prime Contractor's direct labor hours for contract changes, i.e. growth work. The Contractor shall not receive any compensation in addition to this rate for the prime Contractor's direct labor associated with such changes under this contract.

(a) The composite labor hour rate shall represent total compensation for the following: (1) direct labor wages and salaries; (2) all employee benefits including, but not limited to, paid leave, supplemental pay, insurance, retirement, savings, and legally required benefits; (3) other direct costs associated with transit time, delay, disruption, expendable supplies, and equipment; (4) all indirect costs such as overhead and general and administrative expense; (5) any port or association fees, rents, or other levies; (6) profit (fee); and (7) all direct and indirect costs and profit associated with the following support functions: Supervision and Management Planning and Estimating Material Handling Housekeeping Engineering Transportation/Drivers Quality Assurance Contract Administration Security Testing

(b) The composite labor hour rate will be applied to production labor hours only. Production labor hours include only those hours necessary and reasonable to perform direct production functions and do not include the hours expended on the support functions listed above. This exclusion of support function hours applies whether such support functions are normally charged directly or indirectly by the Contractor's accounting system. These support functions are to be priced into the composite labor rate quoted and shall not be separately compensated.

(c) The Quantity of Composite Labor hours indicated in the Schedule of Supplies/Services, is only an estimate and is an Optional Item pursuant to this solicitation. The Estimated Quantity represents the Government's best estimate of the total number of additional hours that may be required throughout the contract. The Government may elect to exceed this value at the prices stated in the schedule and its discretion during performance of the contract. The inclusion of this item does not obligate the Government to exercise the item nor entitle the Contractor to compensation if not exercised.

CONTRACTING OFFICER'S AUTHORITY

No oral or written statement of any person other than the Contracting Officer will in any manner or degree modify or otherwise affect the terms of this contract. The Contracting Officer is the only person authorized to approve changes in any of the requirements under this contract, and, notwithstanding any provisions contained elsewhere in this contract, said authority remains solely with the Contracting Officer. In the event the Contractor effects any such change at the direction of any person other than the Contracting Officer, the change will be considered to have been made without authority and no adjustment will be made in the contract price to cover any increase in cost incurred as a result thereof.

CONTRACT DEFICIENCY REPORT

The Contracting Officer or Contracting Officer's Technical Representative (COTR) may issue a Contract Deficiency Report (CDR), MLCA Form 005. The Contractor shall respond in writing within 24 hours of receipt, unless otherwise approved by the Contracting Officer, to the COTR. The COTR will comment on the Contractor's response and will forward the Deficiency Report and comments to the Contracting Officer, with a copy to the Contractor, the PBPL Availability Project Manager, and the NESU. The Contracting Officer will render a final determination and provide it to the Contractor and COTR in writing.

WARRANTY All applicable commercial warranties for parts and labor are incorporated into this contract.

(End of FAR 52.212-4 Addendum)

52.212-5 -- Contract Terms and Conditions Required to Implement Statutes or Executive Orders -- Commercial Items. As prescribed in 12.301(b)(4), insert the following clause: Contract Terms and Conditions Required to Implement Statutes or Executive Orders -- Commercial Items (Nov 2011) (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (1) 52.222-50, Combating Trafficking in Persons (FEB 2009) (22 U.S.C. 7104(g)). ____ Alternate I (AUG 2007) of 52.222-50 (22 U.S.C. 7104(g)). (2) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553). (3) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78). (b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] ___ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 253g and 10 U.S.C. 2402). ___ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (Pub. L. 110-252, Title VI, Chapter 1 (41 U.S.C. 251 note)). ___ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub L. 111-5) (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009). ___ (4) 52.204-10, Reporting Executive compensation and First-Tier Subcontract Awards (Jul 2010) (Pub. L. 109-282) (31 U.S.C. 6101 note). ___ (5) 52.204-11, American Recovery and Reinvestment Act-Reporting Requirements (Jul 2010) (Pub. L. 111-5). __X_ (6) 52.209-6, Protecting the Government' Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Dec 2010) (31 U.S.C. 6101 note). _X__ (7) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (section 740 of Division C of Public Law 111-117, section 743 of Division D of Public Law 111-8, and section 745 of Division D of Public Law 110-161). ___ (8) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a). ___ (9) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Jan 2011) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C. 657a). ___ (10) [Reserved] _X__ (11) (i) 52.219-6, Notice of Total Small Business Aside (Nov 2011) (15 U.S.C. 644). ___ (ii) Alternate I (Nov 2011). ___ (iii) Alternate II (Nov 2011). ___ (12) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644). ___ (ii) Alternate I (Oct 1995) of 52.219-7. ___ (iii) Alternate II (Mar 2004) of 52.219-7. ___ (13) 52.219-8, Utilization of Small Business Concerns (Jan 2011) (15 U.S.C. 637(d)(2) and (3)). ___ (14) (i) 52.219-9, Small Business Subcontracting Plan (Jan 2011) (15 U.S.C. 637 (d)(4).) ___ (ii) Alternate I (Oct 2001) of 52.219-9. ___ (iii) Alternate II (Oct 2001) of 52.219-9. ___ (iv) Alternate III (July 2010) of 52.219-9. ___ (15) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)). ___ (16) 52.219-14, Limitations on Subcontracting (Nov 2011) (15 U.S.C. 637(a)(14)). ___ (17) 52.219-16, Liquidated Damages-Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)). ___ (18) (i) 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns (Oct 2008) (10 U.S.C. 2323) (if the offeror elects to waive the adjustment, it shall so indicate in its offer). ___ (ii) Alternate I (June 2003) of 52.219-23. ___ (19) 52.219-25, Small Disadvantaged Business Participation Program-Disadvantaged Status and Reporting (Dec 2010) (Pub. L. 103-355, section 7102, and 10 U.S.C. 2323). ___ (20) 52.219-26, Small Disadvantaged Business Participation Program-Incentive Subcontracting (Oct 2000) (Pub. L. 103-355, section 7102, and 10 U.S.C. 2323). ___ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657f). _X__ (22) 52.219-28, Post Award Small Business Program Rerepresentation (Apr 2009) (15 U.S.C. 632(a)(2)). ___ (23) 52.219-29, Notice of Set-Aside for Economically Disadvantaged Women-Owned Small Business Concerns (Nov 2011). ___ (24) 52.219-30, Notice of Set-Aside for Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Nov 2011). __X_ (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755). __X_ (26) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Jul 2010) (E.O. 13126). __X_ (27) 52.222-21, Prohibition of Segregated Facilities (Feb 1999). _X__ (28) 52.222-26, Equal Opportunity (Mar 2007) (E.O. 11246). _X__ (29) 52.222-35, Equal Opportunity for Veterans (Sep 2010) (38 U.S.C. 4212). _X__ (30) 52.222-36, Affirmative Action for Workers with Disabilities (Oct 2010) (29 U.S.C. 793). _X__ (31) 52.222-37, Employment Reports on Veterans (Sep 2010) (38 U.S.C. 4212). __X_ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). __X_ (33) 52.222-54, Employment Eligibility Verification (Jan 2009). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.) ___ (34) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.) ___ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.) ___ (35) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b). ___ (36) (i) 52.223-16, IEEE 1680 Standard for the Environmental Assessment of Personal Computer Products (Dec 2007) (E.O. 13423). ___ (ii) Alternate I (Dec 2007) of 52.223-16. __X_ (37) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging while Driving (Aug 2011). ___ (38) 52.225-1, Buy American Act--Supplies (Feb 2009) (41 U.S.C. 10a-10d). __X_ (39) (i) 52.225-3, Buy American Act -Free Trade Agreements - Israeli Trade Act (Jun 2009) (41 U.S.C. 10a-10d, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, Pub. L. 108-77, 108-78, 108-286, 108-301, 109-53, 109-169, 109-283, and 110-138). ___ (ii) Alternate I (Jan 2004) of 52.225-3. ___ (iii) Alternate II (Jan 2004) of 52.225-3. ___ (40) 52.225-5, Trade Agreements (Nov 2011) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note). __X_ (41) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). ___ (42) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150). ___ (43) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150). ___ (44) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 255(f), 10 U.S.C. 2307(f)). ___ (45) 52.232-30, Installment Payments for Commercial Items (Oct 1995) (41 U.S.C. 255(f), 10 U.S.C. 2307(f)). __X_ (46) 52.232-33, Payment by Electronic Funds Transfer-Central Contractor Registration (Oct. 2003) (31 U.S.C. 3332). ___ (47) 52.232-34, Payment by Electronic Funds Transfer-Other Than Central Contractor Registration (May 1999) (31 U.S.C. 3332). ___ (48) 52.232-36, Payment by Third Party (Feb 2010) (31 U.S.C. 3332). ___ (49) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a). __X_ (50) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). ___ (ii) Alternate I (Apr 2003) of 52.247-64. (c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] ___ (1) 52.222-41, Service Contract Act of 1965 (Nov 2007) (41 U.S.C. 351, et seq.). ___ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 1989) (29 U.S.C. 206 and 41 U.S.C. 351, et seq.). ___ (3) 52.222-43, Fair Labor Standards Act and Service Contract Act -- Price Adjustment (Multiple Year and Option Contracts) (Sep 2009) (29 U.S.C.206 and 41 U.S.C. 351, et seq.). ___ (4) 52.222-44, Fair Labor Standards Act and Service Contract Act -- Price Adjustment (Sep 2009) (29 U.S.C. 206 and 41 U.S.C. 351, et seq.). ___ (5) 52.222-51, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (Nov 2007) (41 U.S.C. 351, et seq.). ___ (6) 52.222-53, Exemption from Application of the Service Contract Act to Contracts for Certain Services--Requirements (Feb 2009) (41 U.S.C. 351, et seq.). ___ (7) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (Mar 2009) (Pub. L. 110-247). ___ (8) 52.237-11, Accepting and Dispensing of $1 Coin (Sep 2008) (31 U.S.C. 5112(p)(1)). (d) Comptroller General Examination of Record The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records -- Negotiation. (1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract. (2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved. (3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law. (e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c) and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause- (i) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (Pub. L. 110-252, Title VI, Chapter 1 (41 U.S.C. 251 note)). (ii) 52.219-8, Utilization of Small Business Concerns (Dec 2010) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $650,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities. (iii) [Reserved] (iv) 52.222-26, Equal Opportunity (Mar 2007) (E.O. 11246). (v) 52.222-35, Equal Opportunity for Veterans (Sep 2010) (38 U.S.C. 4212). (vi) 52.222-36, Affirmative Action for Workers with Disabilities (Oct 2010) (29 U.S.C. 793). (vii) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40. (viii) 52.222-41, Service Contract Act of 1965, (Nov 2007), (41 U.S.C. 351, et seq.) (ix) 52.222-50, Combating Trafficking in Persons (Feb 2009) (22 U.S.C. 7104(g)). ___ Alternate I (Aug 2007) of 52.222-50 (22 U.S.C. 7104(g)). (x) 52.222-51, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (Nov 2007) (41 U.S.C. 351, et seq.) (xi) 52.222-53, Exemption from Application of the Service Contract Act to Contracts for Certain Services--Requirements (Feb 2009) (41 U.S.C. 351, et seq.) (xii) 52.222-54, Employment Eligibility Verification (Jan 2009). (xiii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (Mar 2009) (Pub. L. 110-247). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6. (xiv) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64. (2) While not required, the contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations. (End of Clause) Alternate I (Feb 2000). As prescribed in 12.301(b)(4)(i), delete paragraph (d) from the basic clause, redesignate paragraph (e) as paragraph (d), and revise the reference to "paragraphs (a), (b), (c), or (d) of this clause" in the redesignated paragraph (d) to read "paragraphs (a), (b), and (c) of this clause". Alternate II (Dec 2010). As prescribed in 12.301(b)(4)(ii), substitute the following paragraphs (d)(1) and (e)(1) for paragraphs (d)(1) and (e)(1) of the basic clause as follows: (d) (1) The Comptroller General of the United States, an appropriate Inspector General appointed under section 3 or 8G of the Inspector General Act of 1978 (5 U.S.C. App.), or an authorized representative of either of the foregoing officials shall have access to and right to- (i) Examine any of the Contractor's or any subcontractors' records that pertain to, and involve transactions relating to, this contract; and (ii) Interview any officer or employee regarding such transactions. (e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), and (c), of this clause, the Contractor is not required to flow down any FAR clause in a subcontract for commercial items, other than- (i) Paragraph (d) of this clause. This paragraph flows down to all subcontracts, except the authority of the Inspector General under paragraph (d)(1)(ii) does not flow down; and (ii) Those clauses listed in this paragraph (e)(1). Unless otherwise indicated below, the extent of the flow down shall be as required by the clause- (A) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (Pub. L. 110-252, Title VI, Chapter 1 (41 U.S.C. 251 note)). (B) 52.203-15, Whistleblower Protections Under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub. L. 111-5). (C) 52.219-8, Utilization of Small Business Concerns (Dec 2010) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $650,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities. (D) 52.222-26, Equal Opportunity (Mar 2007) (E.O. 11246). (E) 52.222-35, Equal Opportunity for Veterans (Sept 2010) (38 U.S.C. 4212). (F) 52.222-36, Affirmative Action for Workers with Disabilities (Oct 2010) (29 U.S.C. 793). (G) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40. (H) 52.222-41, Service Contract Act of 1965 (Nov 2007) (41 U.S.C. 351, et seq.). (I) 52.222-50, Combating Trafficking in Persons (Feb 2009) (22 U.S.C. 7104(g)). (J) 52.222-51, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (Nov 2007) (41 U.S.C. 351, et seq.). (K) 52.222-53, Exemption from Application of the Service Contract Act to Contracts for Certain Services--Requirements (Feb 2009) (41 U.S.C. 351, et seq.). (L) 52.222-54, Employment Eligibility Verification (Jan 2009). (M) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (Mar 2009) (Pub. L. 110-247). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6. (N) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-

(6) FAR 52.217-5, Evaluation of Options applies to this acquisition.

Link/URL: https://www.fbo.gov/spg/DHS/USCG/VPLMLCP/HSCG85-12-Q-P45372/listing.html