Z– HOME REPAIRS DR4339PR PUERTO RICO
Notice Type: Modification to a Previous Presolicitation Notice
Posted Date:
Office Address:
Subject: Z-- HOME REPAIRS
Classification Code: Z - Maintenance, repair, and alteration of real property
Solicitation Number: 70FBR218I00000003-01
Contact:
Setaside: N/AN/A
Place of Performance (address): See Statement of Work.
Place of Performance (zipcode): -
Place of Performance Country: -
Description:
Acquisition Operations Division (AOD)
MODIFICATION NOTICE: Bids are being solicited under solicitation number 70FBR218I00000003-01. This announcement constitutes the only solicitation; bids are being requested and a written solicitation will not be issued. The solicitation is issued as an invitation for bids (IFB), unless otherwise indicated herein.If your company can provide the product/services listed on the solicitation and comply with all of the solicitation instructions, please respond to this notice. To view the specifications, please go to www.FedBid.com and reference Buy No. 938304_04. IDIQ: Sellers bidding on this opportunity MUST have the items requested on the specified contract. The contract must either be in the Seller's name or the Seller must be able to document its ability to act as an agent of a partner's contract. Sellers may offer Open Market items only in accordance with the approved Terms and Conditions of their respective contract AND approval from the soliciting contracting officer. This requirement is a [ Small Business ] set-aside and only qualified offerors may submit bids.The solicitation pricing on www.FedBid.com will start on the date this solicitation is posted and will end on 2018-10-16 17:00:00.0 Eastern Time or as otherwise displayed at www.FedBid.com.FOB Destination shall be in the Statement of Work..
52.236-3, Site Investigation and Conditions Affecting the Work
52.236-5, Material and Workmanship
52.243-4" -" Changes
52.236-6, Superintendence by the Contractor
52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements
52.236-11, Use and Possession Prior to Completion
52.246-12, Inspection of Construction
52.236-5, Material and Workmanship
52.236-7, Permits and Responsibilities
52.236-8, Other Contracts,
52.236-10, Operations and Storage Areas.
52.236-12, Cleaning Up
52.236-14, Availability and Use of Utility Services
52.236-15, Schedules for Construction Contracts
52.236-16, Quantity Surveys
52.225-9 Buy American--Construction Materials.
52.232-5, Payments under FP Construction Contracts
52.232-27, Prompt Payment under Construction Contracts
52.246-21, Warranty of Construction
52.236-5, Material and Workmanship
52.246-12, Inspection of Construction
52.211-12, Liquidated Damages, Construction
52.211-18, Variation in Estimated Quantity - Construction
52.236-4, Physical Data
52.236-7, Permits and Responsibilities
52.236-9, Protection of Existing...
52.236-13, Accident Prevention
52.211-10, Commencement, Prosecution, & completion of work
52.211-13 Time Extensions
52.228-3 '-" Workers--
(b) If the Government terminates the Contractor--'s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.
FAR 52.211-13 Time Extensions. Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.
Link/URL: https://www.fbo.gov/spg/DHS/FEMA/PP5-2/70FBR218I00000003-01/listing.html
Hazard Mitigation Technical Assistance Program
Midshipmen Primary Health Insurance Plan
Advisor News
Annuity News
Health/Employee Benefits News
Life Insurance News